200 Contractual Problems and Their Solutions

This book examines 200 contractual problems which regularly arise on building and engineering projects and provides a detailed explanation of their solutions, citing standard contract conditions and key parts of legal judgements as authority. A succinct summary is provided at the end of each detailed solution. It covers problems together with their solutions in respect of: Procurement matters Tenders and bidding Design issues Letters of intent Contractor's programme Contractor's float Delays Concurrent Delays Extensions of time Liquidated/delay damages Unliquidated damages Variations Loss and expense/additional cost claims Acceleration Global claims Payment Damage to the works Exclusion clauses Retention of title Practical completion Defect correction Adjudication This book deals with a broad range of construction contracts including JCT Standard Form and Design and Build, New Engineering Contract NEC3, ICE and GC/Works/1. This book was first published under the title of One Hundred Contractual Problems and Their Solutions , with a second edition entitled One Hundred and Fifty Contractual Problems and their Solutions . This third edition adds 50 new problems and replaces 15 of those in the last edition. Of the remainder half have been the subject of revision. "Deserves a place on every site and in every office as the standard handbook on contractual problems" - Construction Law Digest